Appellant / Complainant
Uppal Chadha Hi-Tech Developers Pvt. Ltd.
Respondent
Aradhna Soni
uppal chadha hi-tech developers pvt. ltd.
₹25,15,001
Respondent
Legal Issues & Claims Raised
Case Procedural History & Progression Tree
Visual step-by-step tree detailing dispute origin, interim hearings, and final tribunal ruling.
Complaint Filing & Dispute Registration
Complaint registered under Case ID 0901126056812022 by Uppal Chadha Hi-Tech Developers Pvt. Ltd. against Aradhna Soni before up_rera.
for delivery of Judgment/Order
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations under Section 18 of the RERA Act for an ongoing project.
Hearing
The Tribunal condoned the delay in filing the appeal, directed the registry to convert the defective appeal into a regular appeal, and reserved judgment after noting that the matter is covered by a previous precedent.
Hearing
The Tribunal has granted a request by the counsels to list this defective appeal for consideration of the application for condonation of delay on 01.10.2024, noting that similar connected matters are scheduled for that date.
Hearing
The Tribunal adjourned the matter and scheduled it for orders/hearing on 09.09.2024 due to the absence of the respondent.
Hearing
The Tribunal granted an adjournment requested by the appellant's counsel on health grounds and scheduled the defective appeal for orders/hearing on 05.07.2024.
Hearing
The Tribunal noted that pleadings have been exchanged and listed the defective appeal for consideration of the application for condonation of delay on 08.05.2024.
Hearing
The Tribunal has ordered the appeal to be listed for a hearing on 05.04.2024.
Hearing
The Tribunal listed the defective appeal for consideration of a delay condonation application and subsequent hearing on March 1, 2024.
Delay condonation
The Tribunal adjourned the proceedings due to a call by the Bar Council of Uttar Pradesh for lawyers to abstain from judicial work and scheduled the matter for hearing on 26.10.2023.
Delay condonation
The Tribunal granted the appellant's counsel three days to file an affidavit of service and scheduled the defective appeal for orders on 26.07.2023.
Delay condonation
The Tribunal directed the issuance of fresh notice to the respondent via post and email due to insufficient address details and set a returnable date of 19.07.2023.
Delay condonation
The Tribunal granted a one-week extension for the appellant to file an affidavit of service and adjourned the matter to May 5, 2023.
Delay condonation
The Tribunal directs the Registry to verify the deposit of Rs. 14,08,381/- by the appellant and orders the issuance of notice to the respondent, subject to successful fund transfer, with a hearing scheduled for 20.04.2023.
Tribunal Order #0901126056812022-02-12-2024
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations under Section 18 of the RERA Act for an ongoing project.
Tribunal Order #0901126056812022-13-03-2023
The Tribunal directs the Registry to verify the deposit of Rs. 14,08,381/- by the appellant and orders the issuance of notice to the respondent, subject to successful fund transfer, with a hearing scheduled for 20.04.2023.
Tribunal Order #0901126056812022-01-10-2024
The Tribunal condoned the delay in filing the appeal, directed the registry to convert the defective appeal into a regular appeal, and reserved judgment after noting that the matter is covered by a previous precedent.
Tribunal Disposal & Final Award Ruling
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations under Section 18 of the RERA Act for an ongoing project. Awarded in favor of Respondent. Awarded interest rate: MCLR+1%.
Final Tribunal Order & Ruling Verdict Summary
Official Ruling Summary
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations under Section 18 of the RERA Act for an ongoing project.
Ruling Awarded To
Respondent
Awarded Interest Rate
MCLR+1%
Interest Period
from 18.07.2016 till the date of obtaining Occupancy/Completion certificate (OC/CC) or till the date of offer of possession whichever is later
Statutory Sections Cited (RERA Act 2016)
Appearing Legal Counsel & Advocates
Appellant Advocate(s)
- Bal Kishor Verma
- Amit Yadav
Respondent Advocate(s)
- Vivek Singh
- Shrey Uttam
- Vatsala Singh
Official RERA Tribunal Orders (3)
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations under Section 18 of the RERA Act for an ongoing project.
The Tribunal directs the Registry to verify the deposit of Rs. 14,08,381/- by the appellant and orders the issuance of notice to the respondent, subject to successful fund transfer, with a hearing scheduled for 20.04.2023.
The Tribunal condoned the delay in filing the appeal, directed the registry to convert the defective appeal into a regular appeal, and reserved judgment after noting that the matter is covered by a previous precedent.
Need to research all rulings for uppal chadha hi-tech developers pvt. ltd.?
Extract builder dossiers, check execution status, and draft RERA appeal petitions in minutes using TathyaGrid.