Appellant / Complainant
Uppal Chadha Hi-Tech Developers Pvt. Ltd.
Respondent
Vikas Agarwal
uppal chadha hi-tech developers pvt. ltd.
₹38,54,715
Respondent
Legal Issues & Claims Raised
Case Procedural History & Progression Tree
Visual step-by-step tree detailing dispute origin, interim hearings, and final tribunal ruling.
Complaint Filing & Dispute Registration
Complaint registered under Case ID 0901126056762022 by Uppal Chadha Hi-Tech Developers Pvt. Ltd. against Vikas Agarwal before up_rera.
for delivery of Judgment/Order
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations for project delays under Section 18 of the RERA Act.
Delay condonation
The Tribunal condoned the delay in filing the appeal and directed the Registry to convert the defective appeal into a regular appeal. After hearing arguments, the Bench reserved judgment, noting that the matter is covered by a previous precedent.
Delay condonation
The Tribunal granted a request by both counsels to club this appeal with similar matters already scheduled for 01.10.2024, directing the case to be listed on that date for orders or hearing.
For Order
The Tribunal has adjourned the appeal to 11.09.2024 for orders following a joint request from the counsel for both parties.
For Order
The Tribunal adjourned the appeal to 08.08.2024 following a request from counsel due to the respondent's representative being delayed by heavy rains and traffic.
For Order
Due to the illness of the appellant's counsel, the court has scheduled a defective appeal for orders on 09.07.2024.
For Order
The Tribunal adjourned the matter to 10.05.2024 for consideration of the application for condonation of delay and hearing, noting the absence of the appellant's counsel due to illness.
For Order
The Tribunal granted the applicant one week's additional time to file a reply to the respondent's objection and scheduled the appeal for hearing on 09.04.2024.
For Order
The Tribunal noted the absence of counsel due to illness and the respondent's non-appearance, subsequently adjourning the matter to 05.03.2024 for consideration of the condonation of delay application.
For Order
The Tribunal granted the appellant 10 days to file a reply to the respondent's objections regarding the application for condonation of delay and grounds of appeal, scheduling the matter for orders on 25.01.2024.
Notice
The Tribunal granted the respondent one week to file objections to the grounds of appeal and directed the applicant to respond to delay condonation objections within a week, scheduling the matter for 28.09.2023.
Delay condonation
The Tribunal accepted the appellant's deposit of Rs. 11,42,762/- under Section 43(5) of the RERA Act and issued notice to the respondent regarding the application for condonation of delay, scheduling the next hearing for 17.08.2023.
Tribunal Order #0901126056762022-02-12-2024
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations for project delays under Section 18 of the RERA Act.
Tribunal Order #0901126056762022-21-06-2023
The Tribunal accepted the appellant's deposit of Rs. 11,42,762/- under Section 43(5) of the RERA Act and issued notice to the respondent regarding the application for condonation of delay, scheduling the next hearing for 17.08.2023.
Tribunal Order #0901126056762022-01-10-2024
The Tribunal condoned the delay in filing the appeal and directed the Registry to convert the defective appeal into a regular appeal. After hearing arguments, the Bench reserved judgment, noting that the matter is covered by a previous precedent.
Tribunal Disposal & Final Award Ruling
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations for project delays under Section 18 of the RERA Act. Awarded in favor of Respondent. Awarded interest rate: MCLR+1%.
Final Tribunal Order & Ruling Verdict Summary
Official Ruling Summary
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations for project delays under Section 18 of the RERA Act.
Ruling Awarded To
Respondent
Awarded Interest Rate
MCLR+1%
Interest Period
from 27.10.2014 till the date of obtaining Occupancy/Completion certificate (OC/CC) or till the date of offer of possession whichever is later
Statutory Sections Cited (RERA Act 2016)
Appearing Legal Counsel & Advocates
Appellant Advocate(s)
- Amit Yadav
- Bal Kishor Verma
Respondent Advocate(s)
- Prasoon Kumar Anjor
Official RERA Tribunal Orders (3)
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations for project delays under Section 18 of the RERA Act.
The Tribunal accepted the appellant's deposit of Rs. 11,42,762/- under Section 43(5) of the RERA Act and issued notice to the respondent regarding the application for condonation of delay, scheduling the next hearing for 17.08.2023.
The Tribunal condoned the delay in filing the appeal and directed the Registry to convert the defective appeal into a regular appeal. After hearing arguments, the Bench reserved judgment, noting that the matter is covered by a previous precedent.
Need to research all rulings for uppal chadha hi-tech developers pvt. ltd.?
Extract builder dossiers, check execution status, and draft RERA appeal petitions in minutes using TathyaGrid.