Appellant / Complainant
Usha Tulsiyan
Respondent
CBS International Projects Private Limited
cbs international projects private limited
₹1,11,65,000
Appellant
Legal Issues & Claims Raised
Case Procedural History & Progression Tree
Visual step-by-step tree detailing dispute origin, interim hearings, and final tribunal ruling.
Complaint Filing & Dispute Registration
Complaint registered under Case ID 0901126015452023 by Usha Tulsiyan against CBS International Projects Private Limited before up_rera.
for delivery of Judgment/Order
The Tribunal partially allowed the appeals, ruling that the developer is liable for delay interest at MCLR+1% from the assured possession date until the offer of possession, granting only a six-month exemption for the COVID-19 pandemic and rejecting all other force majeure claims.
Hearing
The Tribunal heard arguments from both parties regarding the appeal and its objections, subsequently reserving the judgment for a later date.
Hearing
The Tribunal granted an adjournment requested by the respondent's counsel and scheduled the case for orders on July 3, 2025.
Hearing
The Tribunal granted the respondent 10 days to file a reply and scheduled the appeal for hearing on May 2, 2025.
Hearing
The Tribunal has adjourned the appeal to 10.04.2025 upon a joint request from counsel and directed that pleadings be completed by both parties in the interim.
Hearing
The Tribunal granted time to the appellant to rebut an affidavit and to the respondent to file a revised offer regarding alternative shop availability, adjourning the matter to 17.03.2025.
Hearing
The Tribunal granted an adjournment requested by the respondent's counsel due to his absence from the station and rescheduled the matter for orders/hearing on 19.02.2025.
Hearing
The Tribunal granted an adjournment requested by the appellant's counsel due to illness and rescheduled the matter for orders on 29.01.2025.
For Order
The Tribunal recalled the order dated 18.04.2024 and imposed a cost of Rs. 100/- payable to the respondent, subsequently scheduling the appeal for hearing on 06.01.2025.
For Order
The Tribunal has granted a request from the appellant's counsel to list the case for orders on 18.11.2024.
For Order
The Tribunal granted the appellant one week to file a rejoinder to the respondent's objections in RA No. 62/2024 and scheduled the next hearing for October 17, 2024.
For Order
The Tribunal directed the respondent to file objections to the appellant's recall application (RA No. 62/2024) within 10 days and scheduled the matter for hearing on 24.09.2024.
For Order
The appeal was adjourned due to the absence of the appellant's counsel, with the matter rescheduled for orders on 22.08.2024.
For Order
The Tribunal refers the parties to a previous order passed in Appeal No. 213/2023 for further directions.
For Order
The Tribunal granted the appellant one week's time to file a reply to the respondent's objections and scheduled the next hearing for April 18, 2024.
For Order
The Tribunal refers the parties to a previously passed order dated in Appeal No. 213/2023 for the current order.
Admission
The Tribunal granted the appellant one week to submit the application for allotment of the unit and the corresponding Allotment Letter, and scheduled the next hearing for May 1, 2023.
Tribunal Order #0901126015452023-26-09-2025
The Tribunal partially allowed the appeals, ruling that the developer is liable for delay interest at MCLR+1% from the assured possession date until the offer of possession, granting only a six-month exemption for the COVID-19 pandemic and rejecting all other force majeure claims.
Tribunal Order #0901126015452023-18-11-2024
The Tribunal recalled the order dated 18.04.2024 and imposed a cost of Rs. 100/- payable to the respondent, subsequently scheduling the appeal for hearing on 06.01.2025.
Tribunal Disposal & Final Award Ruling
The Tribunal partially allowed the appeals, ruling that the developer is liable for delay interest at MCLR+1% from the assured possession date until the offer of possession, granting only a six-month exemption for the COVID-19 pandemic and rejecting all other force majeure claims. Awarded in favor of Appellant. Awarded interest rate: MCLR+1%.
Final Tribunal Order & Ruling Verdict Summary
Official Ruling Summary
The Tribunal partially allowed the appeals, ruling that the developer is liable for delay interest at MCLR+1% from the assured possession date until the offer of possession, granting only a six-month exemption for the COVID-19 pandemic and rejecting all other force majeure claims.
Ruling Awarded To
Appellant
Awarded Interest Rate
MCLR+1%
Interest Period
from the assured date of possession till the date of offer of possession along with OC/CC excluding six months Covid-19 pandemic period
Statutory Sections Cited (RERA Act 2016)
Appearing Legal Counsel & Advocates
Appellant Advocate(s)
- Vikas Agrawal
Respondent Advocate(s)
- Amit Yadav
Official RERA Tribunal Orders (2)
The Tribunal partially allowed the appeals, ruling that the developer is liable for delay interest at MCLR+1% from the assured possession date until the offer of possession, granting only a six-month exemption for the COVID-19 pandemic and rejecting all other force majeure claims.
The Tribunal recalled the order dated 18.04.2024 and imposed a cost of Rs. 100/- payable to the respondent, subsequently scheduling the appeal for hearing on 06.01.2025.
Need to research all rulings for cbs international projects private limited?
Extract builder dossiers, check execution status, and draft RERA appeal petitions in minutes using TathyaGrid.