Appellant / Complainant
Pushpa
Respondent
Lucknow Development Authority
₹26,30,000
Respondent
Legal Issues & Claims Raised
Case Procedural History & Progression Tree
Visual step-by-step tree detailing dispute origin, interim hearings, and final tribunal ruling.
Complaint Filing & Dispute Registration
Complaint registered under Case ID 0901126015442021 by Pushpa against Lucknow Development Authority before up_rera.
for delivery of Judgment/Order
The Tribunal partially allowed the allottee's appeal by modifying the original order to grant interest for the entire delay period (08.12.2013 to 07.01.2019) and directed that the promoter's pre-deposited amount be transferred to U.P. RERA for disbursement to the allottee.
Further Order
The Tribunal heard arguments regarding the appellant's grievance over the exclusion of specific periods for calculating delay compensation and reserved its judgment on whether arbitration proceedings between the respondent and a contractor can be deducted from the compensation period.
Hearing
The Tribunal directed the parties to submit a list of dates, events, and relied-upon judgments to the Registry and scheduled the appeal for hearing on 22.04.2022.
Further Hearing
The Tribunal clarifies that the matter is not 'part-heard' as previously suggested and directs the appeal to be listed on 05.03.2022 before the concerned Bench according to the roster.
Final Hearing
The Tribunal noted that the case is part-heard before Bench No. I and adjourned the matter to 03.03.2022 for further arguments.
Final Hearing
The Tribunal directed the respondent's counsel to email previously filed response papers to the appellant's counsel and scheduled the appeal for a hearing on 12.01.2022.
Final Hearing
The Tribunal granted the respondent one week to file a response and directed both parties to upload their pleadings to the e-portal before the next hearing on 21.12.2021.
Final Hearing
The Tribunal adjourned the matter to 08.12.2021 to allow the respondent to seek instructions and directed the Registry to summon the records of the original adjudication case.
Delay condonation
The Tribunal noted that pleadings have been exchanged and scheduled the appeal for final hearing on 09.11.2021 before Bench No. 1.
Delay condonation
The Tribunal granted the appellant one week to file a reply to the respondent's objections and directed the matter to be listed on 25.10.2021.
Hearing on Appeal
The Tribunal issued notice to the respondent regarding an application for condonation of delay and directed the parties to exchange documents and file objections via the e-portal before the next hearing on 23.03.2021.
Tribunal Order #0901126015442021-30-06-2022
The Tribunal partially allowed the allottee's appeal by modifying the original order to grant interest for the entire delay period (08.12.2013 to 07.01.2019) and directed that the promoter's pre-deposited amount be transferred to U.P. RERA for disbursement to the allottee.
Tribunal Order #0901126015442021-22-04-2022
The Tribunal heard arguments regarding the appellant's grievance over the exclusion of specific periods for calculating delay compensation and reserved its judgment on whether arbitration proceedings between the respondent and a contractor can be deducted from the compensation period.
Tribunal Disposal & Final Award Ruling
The Tribunal partially allowed the allottee's appeal by modifying the original order to grant interest for the entire delay period (08.12.2013 to 07.01.2019) and directed that the promoter's pre-deposited amount be transferred to U.P. RERA for disbursement to the allottee. Awarded in favor of Respondent. Awarded interest rate: SBI's MCLR+1%.
Final Tribunal Order & Ruling Verdict Summary
Official Ruling Summary
The Tribunal partially allowed the allottee's appeal by modifying the original order to grant interest for the entire delay period (08.12.2013 to 07.01.2019) and directed that the promoter's pre-deposited amount be transferred to U.P. RERA for disbursement to the allottee.
Ruling Awarded To
Respondent
Awarded Interest Rate
SBI's MCLR+1%
Interest Period
from 08.12.2013 to 07.01.2019
Statutory Sections Cited (RERA Act 2016)
Appearing Legal Counsel & Advocates
Appellant Advocate(s)
- Hridesh Srivastava
Respondent Advocate(s)
- Abhishek Khare
Official RERA Tribunal Orders (2)
The Tribunal partially allowed the allottee's appeal by modifying the original order to grant interest for the entire delay period (08.12.2013 to 07.01.2019) and directed that the promoter's pre-deposited amount be transferred to U.P. RERA for disbursement to the allottee.
The Tribunal heard arguments regarding the appellant's grievance over the exclusion of specific periods for calculating delay compensation and reserved its judgment on whether arbitration proceedings between the respondent and a contractor can be deducted from the compensation period.
Need to research all rulings for a builder?
Extract builder dossiers, check execution status, and draft RERA appeal petitions in minutes using TathyaGrid.