Appellant / Complainant
Laureate Buildwell Pvt. Ltd.
Respondent
KV Buildestate LLP
laureate buildwell pvt. ltd.
₹1,47,62,895
Partial
Legal Issues & Claims Raised
Case Procedural History & Progression Tree
Visual step-by-step tree detailing dispute origin, interim hearings, and final tribunal ruling.
Complaint Filing & Dispute Registration
Complaint registered under Case ID 0901126015342020 by Laureate Buildwell Pvt. Ltd. against KV Buildestate LLP before up_rera.
Execution
The Tribunal modified the previous order to grant the appellant promoter a 24-month waiver for delays caused by an NGT injunction and a 6-month waiver for the Covid-19 pandemic, directing the handover of possession and payment of interest accordingly.
Execution
The Tribunal granted an adjournment requested by the appellant's counsel and scheduled the case for orders on January 7, 2026, noting that no further opportunities for adjournment will be provided.
Hearing
The Tribunal granted a request from the appellant's counsel to adjourn the matter and rescheduled the appeal for hearing on 05.12.2025.
Hearing
The Tribunal granted an adjournment requested by the appellant's counsel and rescheduled the appeal for hearing on 26.11.2025.
Hearing
The Tribunal has granted a request from the appellant's counsel to list the appeal for orders or hearing on 05.11.2025.
Hearing
The Tribunal has granted an adjournment and scheduled the appeal for the next hearing on 08.10.2025.
Hearing
The Tribunal granted an adjournment application filed by the appellant's counsel and rescheduled the hearing for 08.09.2025.
Hearing
At the request of the appellant's counsel, the matter is adjourned and scheduled to be listed for orders on 26.08.2025.
Hearing
The Tribunal granted a request for adjournment on behalf of the respondent and scheduled the case for orders on 11.08.2025.
Hearing
The Tribunal granted a request by the appellant's counsel to reschedule the hearing of the appeal to 22.07.2025.
Hearing
The Tribunal granted a request to list the case for orders on 30.05.2025 and directed that a CA certificate be uploaded in the interim.
Hearing
The Tribunal granted an adjournment requested by the appellant's counsel and rescheduled the matter for hearing/orders on 08.05.2025, noting that no further adjournments will be permitted.
Hearing
The Tribunal has adjourned the appeal to 15.04.2025 due to lawyers abstaining from judicial work following a resolution by the Real Estate Bar Association, Lucknow.
Hearing
The Tribunal granted the appellant a one-week extension to file a CA certificate and scheduled the next hearing for March 18, 2025.
Hearing
The Tribunal granted the appellant additional time to comply with the order dated 06.01.2025 and scheduled the next hearing for 27.02.2025, noting that no further extensions will be provided.
Hearing
The Tribunal granted the appellant time to submit a Chartered Accountant's certificate to compute delay interest, specifically requesting the deduction of periods during which NGT injunctions were in effect, and scheduled the next hearing for February 4, 2025.
Hearing
The Tribunal granted an adjournment requested by the appellant's counsel and rescheduled the appeal for hearing on 06.01.2025, noting that no further adjournments will be granted to the appellant.
Hearing
The Tribunal noted that notice was served to the respondent and decided to proceed ex-parte against them, scheduling the matter for an ex-parte hearing on 11-12-2024.
Hearing
The Tribunal directed the Registry to report on the service of notice to the respondent and scheduled the appeal for a hearing on 11.11.2021.
Hearing
The Tribunal scheduled the appeal for hearing on 30.09.2024 and directed the Registry to notify the respondent via email due to their absence.
Hearing
The Tribunal noted the restoration of the appeal and scheduled the matter for hearing on September 2, 2024.
Further Hearing
The appeal filed by M/S Laureate Buildwell Pvt. Ltd. was dismissed for want of prosecution due to the non-appearance of the appellant.
Further Hearing
The Tribunal adjourned the matter to 15.03.2024 due to the non-appearance of the respondent's counsel, noting that the matter will proceed based on available records if no one appears on the next date.
Further Hearing
The Tribunal granted a request from the appellant's counsel to reschedule the hearing of Appeal-489/2020 to 19.02.2024.
Further Hearing
The Tribunal adjourned the proceedings due to a call by the Bar Council of Uttar Pradesh for lawyers to abstain from judicial work, rescheduling the matter for 17.10.2023.
Further Hearing
The Tribunal adjourned the appeal to 11.09.2023 because the counsel for the appellant was on sanctioned leave.
Further Hearing
The proceedings are adjourned because the counsel for the appellant is on sanctioned leave, and the matter is rescheduled for orders on 22.08.2023.
Further Hearing
The Tribunal granted an adjournment requested by the appellant's counsel due to unavoidable circumstances and rescheduled the case for hearing/orders on 04.07.2023.
Further Hearing
The Tribunal granted a request by the appellant's counsel to reschedule the hearing, listing the appeal for 24.04.2023.
Hearing
The Tribunal granted the appellant's request for an adjournment after counsel failed to answer specific queries regarding milestone demands and payments, rescheduling the hearing to 12.05.2023.
Hearing
The Tribunal has ordered a fresh hearing of the appeal because the previous Bench, which had reserved judgment, is no longer available due to the Presiding Member's departure. The matter is rescheduled for hearing on 11.04.2023.
Further Order
The Tribunal heard arguments from both parties regarding the appellant's challenge to penal interest and the 'zero period' interest liability, and subsequently reserved the judgment for future pronouncement.
Hearing
The Tribunal noted that the delay condonation application had already been disposed of and directed the parties to submit a list of dates, events, and relied judgments to the Registry at least three days before the next hearing.
Hearing
The Tribunal granted an adjournment requested by the appellant's counsel due to illness and rescheduled the matter to 15.11.2021 for consideration of the condonation of delay application.
Delay condonation
The Tribunal directed the Registry to verify the deposit of a previously imposed cost of Rs. 1000/- to convert the matter into a regular appeal and scheduled the next hearing for 21.10.2021.
Hearing
The Tribunal granted an adjournment requested by the appellant's counsel due to illness and rescheduled the hearing for the application for condonation of delay to 08.04.2021.
For Order
The Tribunal allowed the application for condonation of delay by 10 days, subject to a cost of Rs. 1,000, and directed the registry to convert the defective appeal into a regular appeal.
For Order
The Tribunal granted the appellant three days to file a reply to the respondent's objection and scheduled the matter for February 23, 2021, to consider the application for condonation of delay.
Tribunal Order #0901126015342020-07-01-2026
The Tribunal modified the previous order to grant the appellant promoter a 24-month waiver for delays caused by an NGT injunction and a 6-month waiver for the Covid-19 pandemic, directing the handover of possession and payment of interest accordingly.
Tribunal Order #0901126015342020-15-03-2024
The appeal filed by M/S Laureate Buildwell Pvt. Ltd. was dismissed for want of prosecution due to the non-appearance of the appellant.
Tribunal Order #0901126015342020-20-09-2021
The Tribunal directed the Registry to verify the deposit of a previously imposed cost of Rs. 1000/- to convert the matter into a regular appeal and scheduled the next hearing for 21.10.2021.
Tribunal Order #0901126015342020-23-02-2021
The Tribunal allowed the application for condonation of delay by 10 days, subject to a cost of Rs. 1,000, and directed the registry to convert the defective appeal into a regular appeal.
Tribunal Order #0901126015342020-06-01-2025
The Tribunal granted the appellant time to submit a Chartered Accountant's certificate to compute delay interest, specifically requesting the deduction of periods during which NGT injunctions were in effect, and scheduled the next hearing for February 4, 2025.
Tribunal Disposal & Final Award Ruling
The Tribunal modified the previous order to grant the appellant promoter a 24-month waiver for delays caused by an NGT injunction and a 6-month waiver for the Covid-19 pandemic, directing the handover of possession and payment of interest accordingly. The appeal filed by M/S Laureate Buildwell Pvt. Ltd. was dismissed for want of prosecution due to the non-appearance of the appellant. Awarded in favor of Partial. Awarded interest rate: Rs.5/- per sqf. w.e.f. 16.07.2015 to 30.04.2016 and MCLR+1% thereafter.
Final Tribunal Order & Ruling Verdict Summary
Official Ruling Summary
The Tribunal modified the previous order to grant the appellant promoter a 24-month waiver for delays caused by an NGT injunction and a 6-month waiver for the Covid-19 pandemic, directing the handover of possession and payment of interest accordingly. The appeal filed by M/S Laureate Buildwell Pvt. Ltd. was dismissed for want of prosecution due to the non-appearance of the appellant.
Ruling Awarded To
Partial
Awarded Interest Rate
Rs.5/- per sqf. w.e.f. 16.07.2015 to 30.04.2016 and MCLR+1% thereafter
Interest Period
w.e.f. 15.07.2015 to 02.11.2020 i.e. till the date of OC/CC
Statutory Sections Cited (RERA Act 2016)
Appearing Legal Counsel & Advocates
Appellant Advocate(s)
- Suchita Singh
Respondent Advocate(s)
- Rajat Gangwar
- Nirmit Srivastav
Official RERA Tribunal Orders (5)
The Tribunal modified the previous order to grant the appellant promoter a 24-month waiver for delays caused by an NGT injunction and a 6-month waiver for the Covid-19 pandemic, directing the handover of possession and payment of interest accordingly.
The appeal filed by M/S Laureate Buildwell Pvt. Ltd. was dismissed for want of prosecution due to the non-appearance of the appellant.
The Tribunal directed the Registry to verify the deposit of a previously imposed cost of Rs. 1000/- to convert the matter into a regular appeal and scheduled the next hearing for 21.10.2021.
The Tribunal allowed the application for condonation of delay by 10 days, subject to a cost of Rs. 1,000, and directed the registry to convert the defective appeal into a regular appeal.
The Tribunal granted the appellant time to submit a Chartered Accountant's certificate to compute delay interest, specifically requesting the deduction of periods during which NGT injunctions were in effect, and scheduled the next hearing for February 4, 2025.
Need to research all rulings for laureate buildwell pvt. ltd.?
Extract builder dossiers, check execution status, and draft RERA appeal petitions in minutes using TathyaGrid.