Appellant / Complainant
Uppal Chadha Hi-Tech Developers Pvt. Ltd.
Respondent
Anita Rathee
uppal chadha hi-tech developers pvt. ltd.
Respondent
Legal Issues & Claims Raised
Case Procedural History & Progression Tree
Visual step-by-step tree detailing dispute origin, interim hearings, and final tribunal ruling.
Complaint Filing & Dispute Registration
Complaint registered under Case ID 0901126014692022 by Uppal Chadha Hi-Tech Developers Pvt. Ltd. against Anita Rathee before up_rera.
Delay condonation
The Tribunal dismissed the appeal filed by Uppal Chadha Hi-Tech Developers Pvt. Ltd., ruling that 'farmers' agitation' does not constitute a 'force majeure' event under the RERA Act 2016 and upholding the Regulatory Authority's order to pay delay interest to the respondent.
Hearing
The Tribunal granted a request for adjournment by the appellant's counsel and rescheduled the appeal for orders to 08.01.2025.
Hearing
The Tribunal noted the filing of a rejoinder by the appellant and scheduled the defective appeal for consideration of the application for condonation of delay on 28.10.2024.
Hearing
The Tribunal granted the appellant seven days to file a reply to the respondent's objections and scheduled the next hearing for September 20, 2024.
Hearing
The Tribunal allowed the respondent's recall application to set aside the order dated 12.04.2024 that had closed their opportunity to file objections, subsequently taking the respondent's objections on record.
Hearing
The Tribunal granted an adjournment due to the respondent's counsel being unable to appear and scheduled the matter to be listed on 19.07.2024 alongside a connected matter.
Hearing
The Tribunal noted the absence of the appellant's counsel and scheduled the defective appeal for a hearing on the application for condonation of delay on 11.07.2024.
Hearing
The Tribunal closed the respondent's opportunity to file objections due to failure to comply with previous orders and scheduled the defective appeal for hearing on 14.05.2024.
Delay condonation
The Tribunal granted a 10-day extension to the respondent to file objections regarding the condonation of delay and grounds of appeal following an adjournment request by the appellant.
Delay condonation
The Tribunal ruled that service of notice to the respondent is sufficient due to multiple delivery attempts and auto-generated RERA notifications, while granting the respondent 10 days to file objections.
Delay condonation
The Tribunal directed the Registry to issue a fresh notice for 01.02.2024 and outlined the procedural steps for the applicant to serve the respondent via email regarding the application for condonation of delay.
Delay condonation
The Tribunal directed the issuance of fresh notice to the respondent via email due to non-compliance with previous directions regarding electronic service, and scheduled the matter for 29.09.2023.
Delay condonation
The Tribunal noted the appellant's deposit of Rs. 13,35,211/- in compliance with Section 43(5) and issued notice to the respondent regarding the application for condonation of delay, scheduling the matter for hearing on 18.08.2023.
Tribunal Order #0901126014692022-08-01-2025
The Tribunal dismissed the appeal filed by Uppal Chadha Hi-Tech Developers Pvt. Ltd., ruling that 'farmers' agitation' does not constitute a 'force majeure' event under the RERA Act 2016 and upholding the Regulatory Authority's order to pay delay interest to the respondent.
Tribunal Order #0901126014692022-19-07-2024
The Tribunal allowed the respondent's recall application to set aside the order dated 12.04.2024 that had closed their opportunity to file objections, subsequently taking the respondent's objections on record.
Tribunal Order #0901126014692022-12-04-2024
The Tribunal closed the respondent's opportunity to file objections due to failure to comply with previous orders and scheduled the defective appeal for hearing on 14.05.2024.
Tribunal Order #0901126014692022-03-07-2023
The Tribunal noted the appellant's deposit of Rs. 13,35,211/- in compliance with Section 43(5) and issued notice to the respondent regarding the application for condonation of delay, scheduling the matter for hearing on 18.08.2023.
Tribunal Disposal & Final Award Ruling
The Tribunal dismissed the appeal filed by Uppal Chadha Hi-Tech Developers Pvt. Ltd., ruling that 'farmers' agitation' does not constitute a 'force majeure' event under the RERA Act 2016 and upholding the Regulatory Authority's order to pay delay interest to the respondent. Awarded in favor of Respondent. Awarded interest rate: MCLR+1 percent.
Final Tribunal Order & Ruling Verdict Summary
Official Ruling Summary
The Tribunal dismissed the appeal filed by Uppal Chadha Hi-Tech Developers Pvt. Ltd., ruling that 'farmers' agitation' does not constitute a 'force majeure' event under the RERA Act 2016 and upholding the Regulatory Authority's order to pay delay interest to the respondent.
Ruling Awarded To
Respondent
Awarded Interest Rate
MCLR+1 percent
Interest Period
from 16.02.2015 till date of offer of possession or date of O.C./C.C., whichever is later
Statutory Sections Cited (RERA Act 2016)
Appearing Legal Counsel & Advocates
Appellant Advocate(s)
- Bal Kishor Verma
- Amit Yadav
Respondent Advocate(s)
- Tushar Bahadur
- Sachin Gupta
Official RERA Tribunal Orders (4)
The Tribunal dismissed the appeal filed by Uppal Chadha Hi-Tech Developers Pvt. Ltd., ruling that 'farmers' agitation' does not constitute a 'force majeure' event under the RERA Act 2016 and upholding the Regulatory Authority's order to pay delay interest to the respondent.
The Tribunal allowed the respondent's recall application to set aside the order dated 12.04.2024 that had closed their opportunity to file objections, subsequently taking the respondent's objections on record.
The Tribunal closed the respondent's opportunity to file objections due to failure to comply with previous orders and scheduled the defective appeal for hearing on 14.05.2024.
The Tribunal noted the appellant's deposit of Rs. 13,35,211/- in compliance with Section 43(5) and issued notice to the respondent regarding the application for condonation of delay, scheduling the matter for hearing on 18.08.2023.
Need to research all rulings for uppal chadha hi-tech developers pvt. ltd.?
Extract builder dossiers, check execution status, and draft RERA appeal petitions in minutes using TathyaGrid.