Appellant / Complainant
Manju Yadav
Respondent
Lucknow Development Authority
₹23,63,000
Partial
Legal Issues & Claims Raised
Case Procedural History & Progression Tree
Visual step-by-step tree detailing dispute origin, interim hearings, and final tribunal ruling.
Complaint Filing & Dispute Registration
Complaint registered under Case ID 0901126010202020 by Manju Yadav against Lucknow Development Authority before up_rera.
for delivery of Judgment/Order
The Appellate Tribunal partially allowed the appeal, modifying the Regulatory Authority's order to direct the Lucknow Development Authority to pay delay interest at the rate of SBI's MCLR+1% for the extended period from 31.05.2012 to 06.07.2019, rejecting the developer's claim that arbitration proceedings constituted force majeure.
Further Hearing
The Tribunal heard arguments from the counsel for both parties and reserved the judgment for a later date.
Further Hearing
The Tribunal adjourned the matter to 21.02.2023 for orders or hearing due to the absence of the respondent's counsel, noting it should be heard alongside Cross Appeal No. 495/2021.
Further Hearing
The Tribunal ordered the appeal to be listed for the following day, 17.02.2023, along with a related appeal (No. D 495/2021).
Hearing
The Tribunal has scheduled the matter to be put up on 16.02.2023 for further orders related to case number D 495/2021.
Hearing
Upon a joint request from the counsels for both parties, the tribunal adjourned the hearing of Appeal-43/2020 to 13.01.2023, to be heard alongside Appeal No. 495/2021.
Further Hearing
The Tribunal noted that pleadings have been exchanged and scheduled the appeal for hearing on 09.12.2022, to be heard alongside Cross Appeal No. (D) 495/2021.
Further Hearing
The Tribunal granted an adjournment application filed by the respondent's counsel and rescheduled the appeal for further hearing on 22.11.2022.
Further Hearing
The Tribunal adjourned the appeal due to the absence of the appellant and scheduled the matter for hearing on 31.10.2022 along with cross Appeal No. (D) 495/2021.
Further Hearing
The Tribunal granted an adjournment requested by the appellant's counsel and scheduled the appeal to be listed on 21.09.2022 along with cross Appeal No. (D) 495/2021.
Further Hearing
The Tribunal adjourned the matter to 28.07.2022 to be heard alongside a cross-appeal filed by the Lucknow Development Authority.
Further Hearing
The Tribunal granted an adjournment requested by the appellant's counsel due to illness and scheduled the appeal for a hearing on 27.07.2022.
Further Hearing
The Tribunal granted a request from the counsels of both parties to adjourn the appeal and list it on 18.07.2022 alongside Appeal No. D 495/2021.
Further Hearing
The Tribunal granted an adjournment requested by the appellant's counsel due to personal difficulty and scheduled the appeal for a hearing on 25.05.2022.
Further Hearing
The Tribunal granted the appellant a final 10-day extension to file a reply to the respondent's objections, subject to a cost of Rs. 1,000/- to be used for the Legal Representatives' Library.
Further Hearing
The Tribunal adjourned the appeal to 21.04.2022 and directed the appellant's counsel to file a replication/rejoinder against the respondent's reply before the next hearing date.
For Order
The Tribunal directed the appellant to file a rejoinder to the respondent's reply within 15 days and scheduled the next hearing for January 21, 2022.
Further Order
The Tribunal adjourned the appeal to 24.12.2021 to be heard alongside connected Appeal No. 495/2021.
Further Order
The Tribunal granted an adjournment requested by the appellant's counsel and rescheduled the case for hearing on 09.12.2021.
Further Order
The Tribunal granted an adjournment requested by the applicant and directed the applicant's counsel to file a rejoinder affidavit, scheduling the next hearing for November 23, 2021.
Hearing
The Tribunal noted the filing of the Vakalat Nama for the respondent and adjourned the matter to 26.10.2021 for further orders.
For Order
The Tribunal granted an adjournment requested by the respondent's counsel due to personal exigency and rescheduled the appeal for hearing on 17.03.2021.
For Order
The Tribunal granted a one-week extension to the appellant for filing a reply to objections and directed parties to upload documents on the e-portal and exchange contact information.
Tribunal Order #0901126010202020-21-04-2022
The Tribunal granted the appellant a final 10-day extension to file a reply to the respondent's objections, subject to a cost of Rs. 1,000/- to be used for the Legal Representatives' Library.
Tribunal Order #0901126010202020-31-05-2023
The Appellate Tribunal partially allowed the appeal, modifying the Regulatory Authority's order to direct the Lucknow Development Authority to pay delay interest at the rate of SBI's MCLR+1% for the extended period from 31.05.2012 to 06.07.2019, rejecting the developer's claim that arbitration proceedings constituted force majeure.
Tribunal Disposal & Final Award Ruling
The Appellate Tribunal partially allowed the appeal, modifying the Regulatory Authority's order to direct the Lucknow Development Authority to pay delay interest at the rate of SBI's MCLR+1% for the extended period from 31.05.2012 to 06.07.2019, rejecting the developer's claim that arbitration proceedings constituted force majeure. Awarded in favor of Partial. Awarded interest rate: MCLR + 1%.
Final Tribunal Order & Ruling Verdict Summary
Official Ruling Summary
The Appellate Tribunal partially allowed the appeal, modifying the Regulatory Authority's order to direct the Lucknow Development Authority to pay delay interest at the rate of SBI's MCLR+1% for the extended period from 31.05.2012 to 06.07.2019, rejecting the developer's claim that arbitration proceedings constituted force majeure.
Ruling Awarded To
Partial
Awarded Interest Rate
MCLR + 1%
Interest Period
from 31.05.2012 to 06.07.2019
Statutory Sections Cited (RERA Act 2016)
Appearing Legal Counsel & Advocates
Appellant Advocate(s)
- Anoop Kumar
Respondent Advocate(s)
- Saurabh Misra
- N A
Official RERA Tribunal Orders (2)
The Tribunal granted the appellant a final 10-day extension to file a reply to the respondent's objections, subject to a cost of Rs. 1,000/- to be used for the Legal Representatives' Library.
The Appellate Tribunal partially allowed the appeal, modifying the Regulatory Authority's order to direct the Lucknow Development Authority to pay delay interest at the rate of SBI's MCLR+1% for the extended period from 31.05.2012 to 06.07.2019, rejecting the developer's claim that arbitration proceedings constituted force majeure.
Need to research all rulings for a builder?
Extract builder dossiers, check execution status, and draft RERA appeal petitions in minutes using TathyaGrid.