Appellant / Complainant
Jagdamba Prasad Pandey
Respondent
Lucknow Development Authority
₹25,14,221
Appellant
Legal Issues & Claims Raised
Case Procedural History & Progression Tree
Visual step-by-step tree detailing dispute origin, interim hearings, and final tribunal ruling.
Complaint Filing & Dispute Registration
Complaint registered under Case ID 0901126005432021 by Jagdamba Prasad Pandey against Lucknow Development Authority before up_rera.
for delivery of Judgment/Order
The U.P. Real Estate Appellate Tribunal allowed the appeals of the allottees and modified the impugned order to grant interest compensation for the entire delayed period (25.05.2012 to 16.02.2019), ruling that the developer's claims regarding farmer agitation and arbitration were not valid 'force majeure' events.
Further Order
The Tribunal heard arguments from both parties and reserved the judgment for future pronouncement.
Further Order
The Tribunal noted the absence of the appellant and directed the appellant to file a replication or rejoinder to the respondent's reply, scheduling the next hearing for 24.01.2022.
Further Order
The Tribunal directed the respondent, Lucknow Development Authority, to file its Vakalatnama and reply to the grounds of appeal within 10 days and scheduled the next hearing for January 4, 2022.
Further Order
The Tribunal directed the respondent's counsel to file a Vakalatnama and a reply to the appeal before the next hearing date. The matter is scheduled for further orders on 30.11.2021.
Hearing
The Tribunal noted that the previous notice to the respondent was improperly addressed and directed the appellant to take steps to re-issue notice, scheduling the next hearing for 29.10.2021.
Hearing on Appeal
The Tribunal issued notice to the Lucknow Development Authority regarding the appeal filed by Jagdamba Prasad Pandey and scheduled the matter for hearing on 17.03.2021.
Tribunal Order #0901126005432021-21-10-2022
The U.P. Real Estate Appellate Tribunal allowed the appeals of the allottees and modified the impugned order to grant interest compensation for the entire delayed period (25.05.2012 to 16.02.2019), ruling that the developer's claims regarding farmer agitation and arbitration were not valid 'force majeure' events.
Tribunal Disposal & Final Award Ruling
The U.P. Real Estate Appellate Tribunal allowed the appeals of the allottees and modified the impugned order to grant interest compensation for the entire delayed period (25.05.2012 to 16.02.2019), ruling that the developer's claims regarding farmer agitation and arbitration were not valid 'force majeure' events. Awarded in favor of Appellant. Awarded interest rate: MCLR+1%.
Final Tribunal Order & Ruling Verdict Summary
Official Ruling Summary
The U.P. Real Estate Appellate Tribunal allowed the appeals of the allottees and modified the impugned order to grant interest compensation for the entire delayed period (25.05.2012 to 16.02.2019), ruling that the developer's claims regarding farmer agitation and arbitration were not valid 'force majeure' events.
Ruling Awarded To
Appellant
Awarded Interest Rate
MCLR+1%
Interest Period
from 25.05.2012 to 16.02.2019
Statutory Sections Cited (RERA Act 2016)
Appearing Legal Counsel & Advocates
Appellant Advocate(s)
- Atul Tripathi
Respondent Advocate(s)
- Amit Yadav
Official RERA Tribunal Orders (1)
The U.P. Real Estate Appellate Tribunal allowed the appeals of the allottees and modified the impugned order to grant interest compensation for the entire delayed period (25.05.2012 to 16.02.2019), ruling that the developer's claims regarding farmer agitation and arbitration were not valid 'force majeure' events.
Need to research all rulings for a builder?
Extract builder dossiers, check execution status, and draft RERA appeal petitions in minutes using TathyaGrid.