Appellant / Complainant
Uppal Chadha Hi-Tech Developers Pvt. Ltd.
Respondent
Nardev Ku Wig.
uppal chadha hi-tech developers pvt. ltd.
₹17,58,120
Respondent
Legal Issues & Claims Raised
Case Procedural History & Progression Tree
Visual step-by-step tree detailing dispute origin, interim hearings, and final tribunal ruling.
Complaint Filing & Dispute Registration
Complaint registered under Case ID 0901126000452023 by Uppal Chadha Hi-Tech Developers Pvt. Ltd. against Nardev Ku Wig. before up_rera.
for delivery of Judgment/Order
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations under Section 18 of the RERA Act for an ongoing project.
Delay condonation
The Tribunal condoned a 13-day delay in filing the appeal and directed the Registry to convert the defective appeal into a regular appeal before reserving judgment.
Delay condonation
The tribunal noted the filing of a Vakalatnama by the respondent's counsel and adjourned the matter to 01.10.2024 for orders/hearing.
Delay condonation
The Tribunal granted the appellant seven days to file a supplementary affidavit and relevant Supreme Court documents, directing that copies be sent to the respondent for objections before the next hearing on 30.08.2024.
Delay condonation
Upon the joint request of the counsels for both parties, the tribunal has rescheduled the hearing for this defective appeal to 30.07.2024.
Delay condonation
The Tribunal noted that pleadings have been exchanged and listed the defective appeal for consideration of a delay condonation application on 02.07.2024.
Delay condonation
The Tribunal noted that pleadings have been exchanged and listed the defective appeal for consideration of the application for condonation of delay on 02.05.2024.
Delay condonation
The Tribunal granted the applicant one week to file a reply to the respondent's objection and scheduled the matter for hearing on 01.04.2024 regarding the application for condonation of delay.
Delay condonation
The Tribunal granted the respondent 10 days to file objections to the application for condonation of delay and directed the matter be listed on 27.02.2024.
Delay condonation
The Tribunal acknowledges the deposit of Rs 9,58,884/- under Section 43(5) of the Act and issues notice to the respondent regarding the application for condonation of delay, scheduled for hearing on 17.01.2024.
Tribunal Order #0901126000452023-02-12-2024
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations under Section 18 of the RERA Act for an ongoing project.
Tribunal Order #0901126000452023-01-10-2024
The Tribunal condoned a 13-day delay in filing the appeal and directed the Registry to convert the defective appeal into a regular appeal before reserving judgment.
Tribunal Order #0901126000452023-19-12-2023
The Tribunal acknowledges the deposit of Rs 9,58,884/- under Section 43(5) of the Act and issues notice to the respondent regarding the application for condonation of delay, scheduled for hearing on 17.01.2024.
Tribunal Disposal & Final Award Ruling
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations under Section 18 of the RERA Act for an ongoing project. Awarded in favor of Respondent. Awarded interest rate: MCLR+1%.
Final Tribunal Order & Ruling Verdict Summary
Official Ruling Summary
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations under Section 18 of the RERA Act for an ongoing project.
Ruling Awarded To
Respondent
Awarded Interest Rate
MCLR+1%
Interest Period
from 31.03.2016 till the date of obtaining Occupancy/Completion certificate (OC/CC) or till the date of offer of possession whichever is later
Statutory Sections Cited (RERA Act 2016)
Appearing Legal Counsel & Advocates
Appellant Advocate(s)
- Amit Yadav
- Bal Kishor Verma
Respondent Advocate(s)
- Sumit Sharma
Official RERA Tribunal Orders (3)
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations under Section 18 of the RERA Act for an ongoing project.
The Tribunal condoned a 13-day delay in filing the appeal and directed the Registry to convert the defective appeal into a regular appeal before reserving judgment.
The Tribunal acknowledges the deposit of Rs 9,58,884/- under Section 43(5) of the Act and issues notice to the respondent regarding the application for condonation of delay, scheduled for hearing on 17.01.2024.
Need to research all rulings for uppal chadha hi-tech developers pvt. ltd.?
Extract builder dossiers, check execution status, and draft RERA appeal petitions in minutes using TathyaGrid.