Appellant / Complainant
Uppal Chadha Hi-Tech Developers Pvt. Ltd.
Respondent
Kiran Seth
uppal chadha hi-tech developers pvt. ltd.
₹14,33,857
Respondent
Legal Issues & Claims Raised
Case Procedural History & Progression Tree
Visual step-by-step tree detailing dispute origin, interim hearings, and final tribunal ruling.
Complaint Filing & Dispute Registration
Complaint registered under Case ID 0901126000442023 by Uppal Chadha Hi-Tech Developers Pvt. Ltd. against Kiran Seth before up_rera.
Hearing
The Tribunal dismissed the appellant's appeal, ruling that delays caused by farmer's agitation do not constitute 'force majeure,' and directed the release of deposited funds to the respondent allottee.
Hearing
The Tribunal granted the appellant seven days to file or upload required documents and scheduled the next hearing for October 6, 2025.
Hearing
The Tribunal heard arguments regarding an appeal against delay interest rates and has adjourned the matter to 08.09.2025 for orders.
For Order
The Tribunal granted the appellant seven days to file a rejoinder affidavit and scheduled the next hearing for August 25, 2025.
For Order
The Tribunal granted the appellant 10 days to file a rejoinder and scheduled the appeal for orders/hearing on August 5, 2025.
Notice
The Tribunal granted the respondent 10 days to file objections, with a subsequent one-week window for any reply, and scheduled the next hearing for July 16, 2025.
Admission
The Tribunal granted the appellant's request to issue fresh notice to the respondent and scheduled the next hearing for May 28, 2025, while outlining the procedural steps for service of notice and filing of objections.
Admission
The appeal is adjourned to 28.04.2025 because lawyers are abstaining from judicial work following a Real Estate Bar Association resolution.
Admission
The Tribunal adjourned the appeal to 28.03.2025 because the learned counsels are abstaining from judicial work following a U.P. Bar Council resolution.
Admission
The Tribunal granted a request from the appellant's counsel to adjourn the matter and rescheduled the case for orders/hearing on 25.02.2025.
Admission
The Tribunal has admitted the appeal, issued notice to the respondent, and set a hearing date for February 4, 2025, while outlining the procedural requirements for service of notice and filing of objections.
Tribunal Order #0901126000442023-06-10-2025
The Tribunal dismissed the appellant's appeal, ruling that delays caused by farmer's agitation do not constitute 'force majeure,' and directed the release of deposited funds to the respondent allottee.
Tribunal Disposal & Final Award Ruling
The Tribunal dismissed the appellant's appeal, ruling that delays caused by farmer's agitation do not constitute 'force majeure,' and directed the release of deposited funds to the respondent allottee. Awarded in favor of Respondent.
Final Tribunal Order & Ruling Verdict Summary
Official Ruling Summary
The Tribunal dismissed the appellant's appeal, ruling that delays caused by farmer's agitation do not constitute 'force majeure,' and directed the release of deposited funds to the respondent allottee.
Ruling Awarded To
Respondent
Statutory Sections Cited (RERA Act 2016)
Appearing Legal Counsel & Advocates
Appellant Advocate(s)
- Surangama Sharma
Respondent Advocate(s)
- Mohini Gupta
Official RERA Tribunal Orders (1)
The Tribunal dismissed the appellant's appeal, ruling that delays caused by farmer's agitation do not constitute 'force majeure,' and directed the release of deposited funds to the respondent allottee.
Need to research all rulings for uppal chadha hi-tech developers pvt. ltd.?
Extract builder dossiers, check execution status, and draft RERA appeal petitions in minutes using TathyaGrid.