Appellant / Complainant
Uppal Chadha Hi-Tech Developers Pvt. Ltd.
Respondent
Pravin Agarwal
uppal chadha hi-tech developers pvt. ltd.
₹19,19,580
Respondent
Legal Issues & Claims Raised
Case Procedural History & Progression Tree
Visual step-by-step tree detailing dispute origin, interim hearings, and final tribunal ruling.
Complaint Filing & Dispute Registration
Complaint registered under Case ID 0901126000432023 by Uppal Chadha Hi-Tech Developers Pvt. Ltd. against Pravin Agarwal before up_rera.
for delivery of Judgment/Order
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations for project delays under Section 18 of the RERA Act.
Delay condonation
The Tribunal condoned a 13-day delay in filing the appeal and directed the Registry to convert the defective appeal into a regular appeal. The matter was heard, and judgment has been reserved.
Delay condonation
The Tribunal granted an adjournment requested by the appellant's counsel due to a scheduling conflict and rescheduled the hearing for October 1, 2024.
Delay condonation
The Tribunal granted the appellant a final seven-day extension to file a supplementary affidavit and relevant Supreme Court documents, with the matter scheduled for hearing on 30.08.2024.
Delay condonation
Upon a joint request from the counsels for both parties, the defective appeal has been adjourned and rescheduled for hearing on 30.07.2024.
Delay condonation
The Tribunal noted that pleadings have been exchanged and listed the defective appeal for hearing on the application for condonation of delay on 02.07.2024.
Delay condonation
The Tribunal noted that pleadings have been exchanged and listed the defective appeal for consideration of the condonation of delay application on 02.05.2024.
Delay condonation
The Tribunal granted the appellant one week to file a reply to the respondent's objection and scheduled the hearing for the application for condonation of delay on 01.04.2024.
Delay condonation
The Tribunal granted the respondent 10 days to file objections to the application for condonation of delay and grounds of appeal, with a subsequent deadline for the applicant to reply.
Delay condonation
The Tribunal issued notice to the respondent regarding the application for condonation of delay and noted the deposit of Rs 10,35,297/- in compliance with Section 43(5) of the Act. The matter is scheduled for hearing on 17.01.2024.
Tribunal Order #0901126000432023-02-12-2024
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations for project delays under Section 18 of the RERA Act.
Tribunal Order #0901126000432023-19-12-2023
The Tribunal issued notice to the respondent regarding the application for condonation of delay and noted the deposit of Rs 10,35,297/- in compliance with Section 43(5) of the Act. The matter is scheduled for hearing on 17.01.2024.
Tribunal Order #0901126000432023-01-10-2024
The Tribunal condoned a 13-day delay in filing the appeal and directed the Registry to convert the defective appeal into a regular appeal. The matter was heard, and judgment has been reserved.
Tribunal Disposal & Final Award Ruling
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations for project delays under Section 18 of the RERA Act. Awarded in favor of Respondent. Awarded interest rate: MCLR+1%.
Final Tribunal Order & Ruling Verdict Summary
Official Ruling Summary
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations for project delays under Section 18 of the RERA Act.
Ruling Awarded To
Respondent
Awarded Interest Rate
MCLR+1%
Interest Period
from 31.03.2016 till the date of obtaining Occupancy/Completion certificate (OC/CC) or till the date of offer of possession whichever is later
Statutory Sections Cited (RERA Act 2016)
Appearing Legal Counsel & Advocates
Appellant Advocate(s)
- Amit Yadav
- Bal Kishor Verma
Respondent Advocate(s)
- Sumit Sharma
Official RERA Tribunal Orders (3)
The Tribunal dismissed the appellant's appeal, ruling that farmer agitation does not constitute 'force majeure' to waive interest obligations for project delays under Section 18 of the RERA Act.
The Tribunal issued notice to the respondent regarding the application for condonation of delay and noted the deposit of Rs 10,35,297/- in compliance with Section 43(5) of the Act. The matter is scheduled for hearing on 17.01.2024.
The Tribunal condoned a 13-day delay in filing the appeal and directed the Registry to convert the defective appeal into a regular appeal. The matter was heard, and judgment has been reserved.
Need to research all rulings for uppal chadha hi-tech developers pvt. ltd.?
Extract builder dossiers, check execution status, and draft RERA appeal petitions in minutes using TathyaGrid.